252.219-7011 Notification to Delay Performance.
Current normalized text
252.219-7011 Notification to Delay Performance.
As prescribed in 219.811-3 (3), use the following clause:
NOTIFICATION TO DELAY PERFORMANCE (JUN 1998)
The Contractor shall not begin performance under this purchase order until 2 working days have passed from the date of its receipt. Unless the Contractor receives notification from the Small Business Administration that it is ineligible for this 8(a) award, or otherwise receives instructions from the Contracting Officer, performance under this purchase order may begin on the third working day following receipt of the purchase order. If a determination of ineligibility is issued within the 2-day period, the purchase order shall be considered canceled.
(End of clause)
Source and use
Source attribution. Official source material is published by Acquisition.gov. ClauseSignal presents a normalized record from accepted public source snapshots and links back to that source.
Informational disclaimer. ClauseSignal provides informational monitoring of public FAR and DFARS source material. It does not provide legal advice, determine whether a clause applies to your circumstances, issue certifications, or claim affiliation with or endorsement by the U.S. Government. Review the official source before making decisions.